整理版電力運(yùn)行維護(hù)合同模板

1、ContractNo.:ICD/NW-2014-OMO&MTechnicalServiceforICDASBEKIRLI#2UNITOF(1+1)x600MWPOWERPLANTCONTRACTO&MTechnicalServiceBetweenICDASELEKTRIKENERJISIURETIMVEYATIRIMA.S.AndSHAANXINORTHWESTPOWERGENERATIONCO.,LTD30thJune,2014O&MTechnicalServiceContractO&M技術(shù)服務(wù)合同PartyA:ICDASELEKTRIKENERJISIURE

2、TIMVEYATIRIMA.S.(ICDAS)甲方：ICDASELEKTRIKENERJISIURETIMVEYATIRIMA.S.(ICDAS)PartyB:SHAANXINORTHWESTPOWERGENERATIONCO.,LTD(CONTRACTOR)乙方：#股份有限公司(承包方)AccordingtoICDASrequirement,CONTRACTORorganizedthefollowingoperationpersonsasICDASemployees,undertheadministrationandmanagementofICDAS,tobeworkinginICDASBE

3、KIRLI#2600MWpowerplant.根據(jù)ICDAS的要求，承包方組織下列運(yùn)行人員，作為ICDAS的雇傭人員，在ICDASBEKIRKI#2600MW電廠工作，接受ICDAS的監(jiān)督和管理。1.PersonandPositionList1.人員和職位列表ItemNo1丁pDepartment部門Position職位NumberofPerson(Q'ty)人員數(shù)1Management1People管理人員1人ProjectManager項(xiàng)目經(jīng)理12Operation29People運(yùn)行人員29名TurbineOperationEngineer汽機(jī)專工1BoilerOperation

4、Engineer鍋爐專工1ElectricalOperationEngineer電氣專工1ChemicalOperationEngineer化學(xué)專工1I&CEngineer熱控專工1ShiftManager值長(zhǎng)4BoilerOperator鍋爐運(yùn)行人員8TurbineOperator汽機(jī)運(yùn)行人員8ElectricalOperator電氣運(yùn)行人員43others6People其它人員6名Interpreter翻譯4Cook廚師2Total總數(shù)36Notes說(shuō)明：1) Theshiftmanagers,shifters,operatorsandtranslatorswillbeworkin

5、gas4shifts(3shiftsinoneday,and1shiftasspare).Generally,themaintenancepersonswillbeworkingindaytime.1)值長(zhǎng)，專工，運(yùn)行人員和翻譯按照4班工作，(4班3倒)，通常檢修人員白天工作。2) Thecontractdurationisdecidedas6monthsplusanother6monthsoptional.2)合同期限為6個(gè)月，可選擇性的加6個(gè)月。ICDAShasrighttoextendtheContractforBekirli#2600MWunitforanother6monthsasa

6、noptionwiththesameunitpriceandconditionsofthisContract,butICDASshouldinformCONTRACTOR1monthbeforetheenddateofthiscontract.Incaseofsuchextension,ICDASwillbeentitledtoincreaseordecreasethenumberofstaff.ICDAS有權(quán)利再延長(zhǎng)Bekiri#2600MW機(jī)組的合同期6個(gè)月，作為本合同同等機(jī)組價(jià)格和條件的一種選擇，但是ICDAS應(yīng)該于此合同結(jié)束前一個(gè)月通知承包方。如果延期，ICDAS有權(quán)增加或者減少人員數(shù)

7、量。2 .Salary2.薪酬Thesalarylevel:USD3,500.00/man-month(inwordsthreethousandfivehundredUSDollars).薪酬為：3500美元/人-月(口頭價(jià)3千5百美元)ThesalarywillbepaidtoCONTRACTORbefore10thofeachmonth,totheaccountpointedbyCONTRACTOR.薪酬于每月的10日前付給承包方指定的賬戶。Paymentshallbesettledtothefollowingbankaccount.支付應(yīng)結(jié)算到下列銀行賬戶：Beneficiary:Sha

8、anxiNorthwestPowerGenerationCo.,Ltd收款人：#股份有限公司NameofBank:SouthAvenueBranch,Xi'anCity,ChinaConstructionBank銀行名：中國(guó)建設(shè)銀行，西安，南大街支行A/C:61014230000220100859賬戶：61014230000220100859SWIFT:PCBCCNBJSXXSWIFT號(hào)：PCBCCNBJSXXThesalaryvalueisnetvalue,withoutanytaxorcustomduty.薪酬價(jià)格為凈值，不含任何稅或者關(guān)稅3 .Benefits3.利益Theabo

9、vesalarylevelincludes:上述薪酬標(biāo)準(zhǔn)包括：1) Thesitestaff'soverseasalary,allowance,subsidyan&ocialsecurityinsurance.1)現(xiàn)場(chǎng)人員的海外工資，補(bǔ)貼，津貼及社會(huì)保險(xiǎn)2) Food,officeconsumable,sitetransportationcost.2)食物，辦公消耗，現(xiàn)場(chǎng)交通成本。3) Dailycommunicationallowance.3)日常通訊津貼。4) AccidentInsurance,maxcompensationis$200,000.00dollars/per

10、occurrenceoneperson.4)意外保險(xiǎn)，最高補(bǔ)償為200000美元/每發(fā)生一人5) Administrativefee,reasonableprofitandtax5)管理費(fèi)，合理的利潤(rùn)及稅收6) Laborsafetyitems,suchasuniform,helmet,shoes,radiosetc.6)勞動(dòng)安全項(xiàng)目，如制服，安全帽，鞋及對(duì)講機(jī)等。Theabovequoteexcludes:上述報(bào)價(jià)不包括：7) PartyAshallprovidePartyBwithworkplace,relevantfacilitiesandwebsite.1)甲方應(yīng)提供乙方工作場(chǎng)地，相關(guān)

11、的設(shè)施及網(wǎng)絡(luò)。8) PartyAshallprovidePartyBwithConvenientlivingcondition,includingconvenientdrinkingwater,showerwater,kitchendeviceandplace,naturalgasforkitchen,electricity,internet,heatingsystem,andnecessaryroutinemaintenance.2)甲方應(yīng)提供乙方便捷的生活條件，包括，便利的飲用水，淋浴水，廚房設(shè)備和場(chǎng)地，廚房用天然氣，電力，互聯(lián)網(wǎng)，供熱系統(tǒng)及必要的日常維護(hù)。9) Thevisaapplic

12、ationcostinTurkeyshallbetakenbyPartyA,andPartyBshallprovideallthedocumentsofrelevantstaff.10) 土耳其簽證申請(qǐng)費(fèi)用由甲方承擔(dān)，乙方應(yīng)提供相應(yīng)人員的所有相關(guān)文件。11) TheairtickettoandfroChina(justoneticketperpersonperoneyear)shallbetakenbyPartyA.4)往返中國(guó)機(jī)票(每年一次)由甲方承擔(dān)。12) PartyAshallberesponsibletothetransportationfromtheIstanbulairportt

13、ojobsite,andviceversa.5)甲方應(yīng)負(fù)責(zé)從伊斯坦布爾到達(dá)現(xiàn)場(chǎng)的往返交通。13) PartyAshallberesponsiblefortax,residentialpermit,workpermit(ifhas)underanytitlesrequiredbythelocalauthority.6)甲方應(yīng)負(fù)責(zé)地方當(dāng)局要求的相關(guān)居住許可，工作許可(如果有)等相關(guān)許可。14) ThestartingtimeoftheworkingperiodwillbethedatefromAug.01.2014.7)工作開(kāi)始時(shí)間為2014年8月1日15) Medicalserviceshoul

14、dbefreeofcharge.8)醫(yī)療服務(wù)為免費(fèi)的。16) Convenientworkingconditions.(Offices)9)便利的工作條(辦公室)。17) Convenientinlandtransportationbetweenlivingareaandsite,outsidetransportationforshoppingandtravelingetc.10)便捷的交通設(shè)施往返于生活區(qū)域和現(xiàn)場(chǎng)，以及方便的購(gòu)物和旅行交通工具。18) ChinesePersonswillwork8hours/day(48hours/week).Ifnecessary,thepersonswi

15、llworkovertimeandICDASshallapproveovertimeworkinghours,extrasalary(US$7dollars/hour-person)mustbepaidbyICDASatsiteatnextsalaryday.11)中國(guó)人員每天工作8小時(shí)(48小時(shí)/周)，如果需要人員加班工作，ICDAS應(yīng)核準(zhǔn)工作時(shí)間，加班薪酬(7美元/每人每小時(shí))，由ICDAS在下一個(gè)工作日，在現(xiàn)場(chǎng)支付。19) WorkinginChineselegalholidays(10days/year)willbeconsideredasworkingovertime,theextr

16、asalary(US$7dollars/hour-person)foralldutymustbepaidbyICDASatsiteatnextsalaryday.12）如果在中國(guó)的法定休假工作（10天/年），視為加班工作，加班工資為（7美元/人/時(shí)）。ICDAS必須在下一個(gè)工作日，現(xiàn)場(chǎng)給予支付。20) Securityinworkingandlivingarea.13）工作及生活區(qū)的安全21) ThesitetrainingofTurkishoperatorsareincludedinthiscontract.22) 土耳其運(yùn)行人員的現(xiàn)場(chǎng)培訓(xùn)也包含在此合同中。4. ForceMajeure4

17、.不可抗力aNeitherCONTRACTORnorICDASshallbeliablefordelayorfailureofperformanceunderthiscontractwheresuchfailureordelayiscausedbyForceMajeure,beinganyevent,occurrenceorcircumstancereasonablybeyondcontrolofeitherparty,includingbutnotlimitedtofailureordelaycausedbyorresultingfromActsofGod,strikes,fires,flo

18、ods,earthquake,landslide,typhoon,cyclone,storm,wars,（whetherdeclaredorundeclared）,riots,delaysofcarriersduetobreakdownimposedbyanygovernmentalauthority（includingallocations,priorities,requisitions,quotas,andpricecontrols）.a承包商或者ICDAS受不可抗力影響無(wú)法履行合同規(guī)定的義務(wù)或者延遲履行的，任一方對(duì)此不承擔(dān)任何責(zé)任。若發(fā)生超出任何一方合理控制范圍內(nèi)的不可抗力事件、不可抗力

19、發(fā)生以及不可抗力情況，包括但不限于天災(zāi)、罷工、火災(zāi)、水災(zāi)、地震、山體滑坡、臺(tái)風(fēng)、颶風(fēng)、暴風(fēng)雨、戰(zhàn)爭(zhēng)（已宣戰(zhàn)或未宣戰(zhàn)）、暴動(dòng)、因政府當(dāng)局頒布的限制性條款（包括配給、優(yōu)先權(quán)、征用、配額及價(jià)格控制等）導(dǎo)致的運(yùn)輸延誤等造成義務(wù)無(wú)法履行或義務(wù)履行延誤。bIftheCONTRACTORisprevented,hinderedordelayedfromorinperforminganyofitsobligationsundertheContractbyaneventofForceMajeure,thenitshallnotifytheICDASinwritingoftheoccurrenceofsuchev

20、entandthecircumstancesthereofwithinfourteen（14）daysaftertheoccurrenceofsuchevent.b如果承包商因不可抗力而被妨礙、阻礙或者延遲履行其在本合同中的任一規(guī)定義務(wù)時(shí)，承包商應(yīng)在不可抗力事件發(fā)生的十四（14）天內(nèi)以書(shū)面形式通知ICDAS此類事件和情況的發(fā)生。cTheCONTRACTORshallbeexcusedfromtheperformanceorpunctualperformanceofitsobligationsundertheContractforsolongastherelevanteventofForceMa

21、jeurecontinuesandtotheextentthattheCONTRACTOR'sperformanceisprevented,hinderedordelayed.Thetimeforcompletionshallbeextendedreasonably.c如果相關(guān)不可抗力事件仍在發(fā)生，而且在一定程度上妨礙、阻礙或者延遲了承包商對(duì)義務(wù)的履行，則應(yīng)予以免除承包商履行本合同中規(guī)定義務(wù)或準(zhǔn)時(shí)履行義務(wù)的責(zé)任。完工時(shí)間應(yīng)適當(dāng)進(jìn)行延長(zhǎng)。dWhileaffectedbytheeventofForceMajeure,theCONTRACTORshallusereasonableeffort

22、stomitigatetheeffectthereofuponitsperformanceoftheContractandshallseekallreasonablealternativemeansforperformancenotpreventedbytheForceMajeure5event.d.當(dāng)受到不可抗力事件影響時(shí)，承包商應(yīng)采用合理措施減少不可抗力事件對(duì)其履行合同義務(wù)的影響，并應(yīng)尋求合理的替代手段履行未受不可抗力影響的義務(wù)。eDelayornon-performanceoftheCONTRACTORheretocausedbytheoccurrenceofanyeventofForc

23、eMajeureshallnot:e因發(fā)生的任何不可抗力事件而延遲或者不能履行義務(wù)的承包商，不應(yīng)：a) ConstituteadefaultorbreachoftheContact;orb) GiverisetoanyclaimfordamagesoradditionalcostorexpenseoccasionedtherebytotheCONTRACTOR;orc) CausetheforfeitingofthePerformanceBondandimposetheliquidateddamagetotheCONTRACTOR.a)構(gòu)成違反或者違背本合同；b)引起任何需承包商承擔(dān)的賠償損失

24、或者額外費(fèi)用或開(kāi)支c)造成履約保證書(shū)失效，向承包商征收違約賠償金。5 TaxesandDuties6 繳稅Alltaxes,customdutiesandotherduesarisinginTurkeyshallbepaidbytheICDAS.在土耳其產(chǎn)生的賦稅，關(guān)稅和其他賦稅將由ICDAS繳納。7 Arbitration8 仲裁AlldisputesintheconnectionwiththeexecutionofthisContractshallbesettledthroughfriendlynegotiationsbetweenthetwoParties.Failingthefrien

25、dlynegotiationdoesnotrelievebothofanyofthepartiesformfulfillingtheContract.InthecaseofbeingunabletosettledisputeseachpartyshallhaverightforarbitrationtoICC(internationalChamberofCommerce)InternationalCourtofArbitrationinaccordancewiththeProvisionalRulesofProceduresPromulgatedbythesaidArbitrationComm

26、ission.TheArbitrationshalltakeplaceinSwitzerlandandSwissmateriallawshallapply.在執(zhí)行本合同時(shí)，所產(chǎn)生的糾紛應(yīng)由雙方友好協(xié)商解決。通過(guò)友好協(xié)商，雙方才能共同完成合同。如果糾紛不能解決，依照仲裁委員會(huì)暫行議事規(guī)程，雙方有權(quán)利向ICC國(guó)際仲裁法院申請(qǐng)仲裁。仲裁在瑞士進(jìn)行，瑞士實(shí)體法適用于仲裁。aTheArbitrationproceedingshallbecarriedoutintheEnglishlanguage.a仲裁過(guò)程將用英語(yǔ)進(jìn)行。bThearbitralawardshallbefinalandbindingonb

27、othParties.b該仲裁裁決為最終裁決，對(duì)雙方均有約束力。cThearbitrationfeeshallbebornebythelosingParty,exceptasotherwisestipulatedinthearbitralaward.c仲裁費(fèi)用由敗訴方承擔(dān)，仲裁裁決中規(guī)定情況除外。9 Effectiveness,Variation,SuspensionandTerminationoftheContractandMiscellaneous10 合同的效力、變更、中止、終止及其它TheContractshallbecomeeffectiveandbindinguponthetwop

28、artiesaftercompletionofallthefollowing:在進(jìn)行完以下各項(xiàng)后，此合同將生效并對(duì)雙方具有約束力：aTheContracthasbeendulysignedbytheauthorizedrepresentativesofbothparties;a合同已經(jīng)由雙方授權(quán)代表如期簽署；bTheeffectivedateoftheContractisfromsignature.b合同生效期自簽署日起。cThisContractshallbewritteninEnglishwithfourcopiesforeachPartyholdingtwocopies.c書(shū)面合同為英文

29、，一式四份，雙方各持有兩份。dMinutesfromallmeetingsbetweenthetwoParties,writteninEnglishifsignedanddecidedbybothparties,shallbecomeAppendicesandthusintegralpartsoftheContract.AllcommercialandtechnicalcommunicationsbetweenthetwoPartiesshallbeintheEnglishlanguage.Ifinwriting,duplicatewillbeproduced.d對(duì)于雙方參與的會(huì)議，如雙方均有

30、簽署或決策，會(huì)議紀(jì)要應(yīng)為英文版本，并作為附件成為合同的一部分。雙方之間的所有商務(wù)和技術(shù)交流均使用英語(yǔ)，若為書(shū)面形式，應(yīng)有復(fù)本。eICDASshallappointoneauthorizedrepresentativetobeinchargeofallcommercialandtechnicalmattersrelatingtotheCONTRACTOR.AnycorrespondencesaddressedtotheICDASrepresentativefromtheCONTRACTORarerequiredintwocopiesonefortherepresentative,onetothe

31、ICDAS.TheICDASshallinformtheCONTRACTORtwoweeksaftertheeffectivedateoftheContractofthenameoftheauthorizedrepresentativeandhispostaladdress.eICDAS將任命一名授權(quán)代表全權(quán)負(fù)責(zé)所有和承包方相關(guān)的商務(wù)及技術(shù)事宜。承包方發(fā)給ICDAS代表的所有往來(lái)函件均需提供復(fù)制兩份，ICDAS和代表各持一份。ICDAS應(yīng)在合同生效日兩周內(nèi)通知承包方被授權(quán)代表的人名及郵寄地址。fWhereforreasonsoccurringintheICDASscountryandnotof

32、theCONTRACTORjintention,theCONTRACTORispreventedfromcontinuingwiththeContractforaperiod,thetwopartiesshallcornetonegotiationandifnecessarytheICDASmaysuspendtheContract.TheICDASshallbearanyexpensesincurredbytheCONTRACTORduringtheperiodofSuspensionthataretobeagreeduponbythetwoParties.f如由于ICDAS所在國(guó)家的原因，

33、而非承包方的原因造成承包方無(wú)法繼續(xù)合同，雙方應(yīng)進(jìn)行協(xié)商，如有必要ICDAS會(huì)中止合同。在合同中止期間(需雙方一致同意)，ICDAS將會(huì)承擔(dān)承包方的任何損失。gTheICDASshallhavetherightatanytimeforanyreasontoterminatethewholeorpartoftheContractbygivingwrittennoticetotheCONTRACTORspecifyingtheextentandtheeffectivedateofsuchtermination.TheICDASwillpaytheCONTRACTORthefollowingamoun

34、t:gICDAS有權(quán)在任何時(shí)間由于任何原因終止整個(gè)或部分合同，并向承包方給出書(shū)面通知具體說(shuō)明合同終結(jié)的范圍及生效日期。ICDAS將會(huì)向承包商支付以下款項(xiàng)：(1) PaymentforallorpartoftheWorksproperlyperformedaccordingtotheContractandtherelevantexpensespriortothedateoftermination.(1)在合同終結(jié)日前按照合同已執(zhí)行的全部或部分工作，其應(yīng)付款項(xiàng)及相關(guān)費(fèi)用。(2) Anyotheractualreasonableandnecessarydirectexpenses,suchasair

35、ticket,transportationcost,etc(2)其它實(shí)際發(fā)生的合理且必需的直接費(fèi)用，如機(jī)票、交通費(fèi)用等。hAnycorrespondence,noticeorrequestgivenbyeitherPartytotheotherPartyshallbedeemedtohavebeenofficiallygivenifinwritinganddeliveredpersonally,forwardedbyregisteredorcertifiedairmail,cabled,facsimiledbytelefaxortelexedandaddressedtosuchPartyina

36、ccordancetotheofficialaddress,telephone.Telexandtelefaxhereof,andifconfirmationorreceiptisacknowledgedbythereceivingPartyand/orhisfacilitiesoftheCommunication.h任何一方向另一方發(fā)出的手簽信函、通知或要求，以及接收方及(或)其設(shè)備認(rèn)可的函證或收據(jù)，都應(yīng)通過(guò)書(shū)面方式進(jìn)行，并親自遞送，或通過(guò)已登記或具有證明文件的航空郵件，電報(bào)、傳真轉(zhuǎn)送發(fā)往此方的官方地址、電話、電報(bào)及傳真。Alltheamendments,supplementandalter

37、ationstothetermsandconditionsoftheContractshallbemadeinwrittenformandsignedbytheauthorizedrepresentativesofthetwoPartiesandshallconstituteanintegralpartoftheContractandhavethesamelegalforceastheContract.合同中所有關(guān)于術(shù)語(yǔ)和條件的修訂、補(bǔ)充、變更都應(yīng)經(jīng)過(guò)書(shū)面形式進(jìn)行，并由雙方授權(quán)代表簽字，同時(shí)作為合同的一部分存在，和合同具有同等法律效力。a.TheCONTRACTORhastherighttot

38、erminatethecontractandtheemployeepersonswillstoptheservicesinpowerplantifICDASdon'Ipaythesalaryandbenefitsstipulatedinthecontract.ThisterminationwillbeinformedbywrittenformtoICDAS10daysbeforetherealaction.ThisactionwillnotinfluencetherightforCONTRACTORtoclaimfurthercompensation.a.如果ICDAS未按照合同支付薪酬及福利，承包方有權(quán)終止合同并停止對(duì)電廠的服務(wù)。合同終止的通知應(yīng)在實(shí)際停止服務(wù)前10天通過(guò)書(shū)面形式通知ICD