2024版機(jī)場航站樓鋁合金門窗系統(tǒng)設(shè)計(jì)與施工合同

甲方：XXX乙方：XXX20XXCOUNTRACTCOVER專業(yè)合同封面RESUME甲方：XXX乙方：XXX20XXCOUNTRACTCOVER專業(yè)合同封面RESUMEPERSONAL

2024版機(jī)場航站樓鋁合金門窗系統(tǒng)設(shè)計(jì)與施工合同本合同目錄一覽第一條合同主體及定義1.1設(shè)計(jì)方主體1.2施工方主體1.3甲方主體1.4乙方主體第二條設(shè)計(jì)與施工內(nèi)容2.1設(shè)計(jì)內(nèi)容2.2施工內(nèi)容2.3設(shè)計(jì)與施工協(xié)調(diào)第三條合同金額與支付方式3.1合同金額3.2支付方式3.3進(jìn)度付款3.4變更付款第四條設(shè)計(jì)與施工期限4.1設(shè)計(jì)期限4.2施工期限4.3延期規(guī)定第五條質(zhì)量標(biāo)準(zhǔn)與要求5.1設(shè)計(jì)質(zhì)量標(biāo)準(zhǔn)5.2施工質(zhì)量標(biāo)準(zhǔn)5.3驗(yàn)收標(biāo)準(zhǔn)第六條技術(shù)與資料交換6.1設(shè)計(jì)資料提供6.2施工資料提供6.3技術(shù)與資料協(xié)調(diào)第七條變更與調(diào)整7.1變更程序7.2變更費(fèi)用7.3變更執(zhí)行第八條違約責(zé)任8.1設(shè)計(jì)方違約8.2施工方違約8.3甲方違約8.4乙方違約第九條爭議解決9.1協(xié)商解決9.2調(diào)解解決9.3仲裁解決9.4法律途徑第十條保險(xiǎn)責(zé)任10.1設(shè)計(jì)方保險(xiǎn)10.2施工方保險(xiǎn)10.3甲方保險(xiǎn)10.4乙方保險(xiǎn)第十一條合同的生效、變更與終止11.1合同生效條件11.2合同變更程序11.3合同終止條件第十二條保密條款12.1保密內(nèi)容12.2保密期限12.3泄露后果第十三條環(huán)境影響與安全13.1環(huán)境影響評(píng)估13.2安全生產(chǎn)措施13.3應(yīng)急預(yù)案第十四條其他條款14.1不可抗力14.2法律適用14.3爭議解決14.4附件說明第一部分：合同如下：第一條合同主體及定義1.1設(shè)計(jì)方主體designatingbody：指根據(jù)本合同規(guī)定負(fù)責(zé)鋁合金門窗系統(tǒng)設(shè)計(jì)的服務(wù)提供方。1.2施工方主體constructionbody：指根據(jù)本合同規(guī)定負(fù)責(zé)鋁合金門窗系統(tǒng)施工的服務(wù)提供方。1.3甲方主體partyA：指委托設(shè)計(jì)方和施工方進(jìn)行鋁合金門窗系統(tǒng)設(shè)計(jì)與施工的法人或其他組織。1.4乙方主體partyB：指設(shè)計(jì)方和施工方的法人或其他組織。第二條設(shè)計(jì)與施工內(nèi)容2.1設(shè)計(jì)內(nèi)容designcontent：包括鋁合金門窗系統(tǒng)的設(shè)計(jì)方案、施工圖紙、技術(shù)說明、材料清單等。2.2施工內(nèi)容constructioncontent：包括鋁合金門窗系統(tǒng)的安裝、調(diào)試、驗(yàn)收等施工過程。2.3設(shè)計(jì)與施工協(xié)調(diào)designandconstructioncoordination：設(shè)計(jì)方和施工方應(yīng)保持密切溝通，確保設(shè)計(jì)與施工的順利進(jìn)行。第三條合同金額與支付方式3.1合同金額contractamount：雙方根據(jù)設(shè)計(jì)和施工內(nèi)容商定的合同金額，具體金額在合同附件中詳細(xì)列明。3.2支付方式paymentmethod：甲方按照設(shè)計(jì)和施工進(jìn)度，分階段支付合同金額。具體支付方式在合同附件中詳細(xì)列明。3.3進(jìn)度付款progresspayment：甲方根據(jù)設(shè)計(jì)和施工進(jìn)度，按照合同約定的比例支付合同金額。3.4變更付款changepayment：如合同內(nèi)容發(fā)生變更，雙方根據(jù)變更金額商定支付方式。第四條設(shè)計(jì)與施工期限4.1設(shè)計(jì)期限designperiod：設(shè)計(jì)方根據(jù)合同約定完成設(shè)計(jì)任務(wù)的時(shí)間，具體期限在合同附件中詳細(xì)列明。4.2施工期限constructionperiod：施工方根據(jù)合同約定完成施工任務(wù)的時(shí)間，具體期限在合同附件中詳細(xì)列明。4.3延期規(guī)定delayregulations：如因不可抗力等原因?qū)е略O(shè)計(jì)和施工進(jìn)度延誤，雙方根據(jù)實(shí)際情況商定延期期限。第五條質(zhì)量標(biāo)準(zhǔn)與要求5.1設(shè)計(jì)質(zhì)量標(biāo)準(zhǔn)designqualitystandards：設(shè)計(jì)方應(yīng)按照合同約定的技術(shù)要求、規(guī)范和標(biāo)準(zhǔn)完成設(shè)計(jì)任務(wù)，確保設(shè)計(jì)質(zhì)量。5.2施工質(zhì)量標(biāo)準(zhǔn)constructionqualitystandards：施工方應(yīng)按照合同約定的技術(shù)要求、規(guī)范和標(biāo)準(zhǔn)完成施工任務(wù)，確保施工質(zhì)量。5.3驗(yàn)收標(biāo)準(zhǔn)acceptancestandards：雙方按照合同約定的驗(yàn)收規(guī)范和標(biāo)準(zhǔn)進(jìn)行驗(yàn)收，確保工程質(zhì)量符合要求。第六條技術(shù)與資料交換6.1設(shè)計(jì)資料提供designinformationprovision：設(shè)計(jì)方應(yīng)按照合同約定的時(shí)間和方式向施工方提供設(shè)計(jì)資料，包括設(shè)計(jì)方案、施工圖紙等。6.2施工資料提供constructioninformationprovision：施工方應(yīng)按照合同約定的時(shí)間和方式向設(shè)計(jì)方提供施工資料，包括施工進(jìn)度、施工情況等。6.3技術(shù)與資料協(xié)調(diào)technologyandinformationcoordination：雙方應(yīng)保持密切溝通，及時(shí)解決設(shè)計(jì)和施工過程中遇到的問題，確保工程順利進(jìn)行。第八條違約責(zé)任8.1設(shè)計(jì)方違約8.2施工方違約8.3甲方違約8.4乙方違約第九條爭議解決9.1協(xié)商解決ThepartiesshallfirstresolveanydisputesarisingoutoforinconnectionwiththisContractthroughfriendlynegotiation.9.2調(diào)解解決Ifthedisputescannotberesolvedthroughnegotiation,eitherpartymaysubmitthedisputestoapeople'scourtwithjurisdictionattheplaceofperformanceofthemaincontractortoanarbitrationinstitutionagreedthepartiesforarbitration.9.3仲裁解決Ifthepartieshaveagreedtoarbitrate,thedisputesarisingoutoforinconnectionwiththisContractshallbesubmittedtotheChinaInternationalEconomicandTradeArbitrationCommission(CIETAC)forarbitrationinaccordancewithitsrules.9.4法律途徑Ifthepartiesareunabletoresolvethedisputesthroughnegotiationorarbitration,theymayresorttolegalproceedingsinthePeople'sCourtofthePeople'sRepublicofChina.第十條保險(xiǎn)責(zé)任10.1設(shè)計(jì)方保險(xiǎn)10.2施工方保險(xiǎn)10.3甲方保險(xiǎn)10.4乙方保險(xiǎn)第十一條合同的生效、變更與終止11.1合同生效條件11.2合同變更程序AnyamendmentormodificationofthisContractmustbemadeinwritingandexecutedthepartieshereto.11.3合同終止條件第十二條保密條款12.1保密內(nèi)容12.2保密期限ThepartiesshallmaintaintheconfidentialityoftheConfidentialInformationforaperiodof[insertperiod]yearsfromthedateofthisContract.12.3泄露后果IfthereceivingpartybreachesthisSection,itshallbeliabletothedisclosingpartyforalldamages,losses,orexpensessufferedorincurredthedisclosingpartyasaresultofsuchbreach.第十三條環(huán)境影響與安全13.1環(huán)境影響評(píng)估Thepartiesshallcarryoutanenvironmentalimpactassessmentinaccordancewithapplicablelawsandregulationsandtakenecessarymeasures第二部分：第三方介入后的修正第十四條第三方介入14.1定義ForthepurposesofthisContract,"ThirdParty"meansanyindividual,entityororganizationthatisnotthepartiestothisContractandisinvolvedintheperformanceofthisContract.14.2第三方責(zé)任TheThirdPartyshallberesponsiblefortheperformanceofthetasksassignedtoitunderthisContractandshallbeliableforanydirectlossescauseditsbreachofcontractornegligence.14.3第三方選擇Thepartiesmay,attheirsolediscretion,selectaThirdPartytoperformcertaintasksunderthisContract.TheselectionofaThirdPartyshallbesubjecttothepriorwrittenconsentoftheotherparty.14.4第三方支付ThepartiesshallberesponsiblefornegotiatinganddeterminingthepaymenttermsfortheservicesprovidedtheThirdParty.ThepaymenttermsshallbesetforthinwritingandattachedasanannextothisContract.14.5第三方責(zé)任限額TheliabilityoftheThirdPartyunderthisContractshallbelimitedtotheextentspecifiedintherelevantannexorattachmenthereto.第十五條額外條款及說明15.1第三方義務(wù)TheThirdPartyshallbeboundthetermsandconditionsofthisContractandshallperformitsobligationsinaccordancewiththerequirementsoftheparties.15.2第三方與甲乙方的關(guān)系TheThirdPartyshallhavenorelationshipwiththepartiestothisContractotherthanasprovidedforinthisContract.15.3第三方違約處理IntheeventofabreachofcontractordefaulttheThirdParty,thepartiesshallhavetherighttotakelegalactionagainsttheThirdPartyinaccordancewiththetermsofthisContract.15.4第三方權(quán)利限制TheThirdPartyshallnothaveanyrightsunderthisContractotherthanthoseexpresslyprovidedforinthisContract.15.5第三方解除合同TheThirdPartymaynotterminatethisContractunlessthepartiesagreeinwritingtosuchtermination.第十六條第三方概念與責(zé)任劃分16.1第三方概念ForthepurposesofthisContract,"ThirdParty"meansanyindividual,entityororganizationthatisnotthepartiestothisContractandisinvolvedintheperformanceofthisContract.16.2第三方責(zé)任劃分TheThirdPartyshallberesponsiblefortheperformanceofthetasksassignedtoitunderthisContractandshallbeliableforanydirectlossescauseditsbreachofcontractornegligence.ThepartiesshallnotbeliableforanyactsoromissionsoftheThirdParty.16.3第三方與甲乙方的關(guān)系劃分TheThirdPartyshallhavenorelationshipwiththepartiestothisContractotherthanasprovidedforinthisContract.ThepartiesshallnotberesponsibleforanyactsoromissionsoftheThirdParty.16.4第三方違約處理劃分IntheeventofabreachofcontractordefaulttheThirdParty,thepartiesshallhavetherighttotakelegalactionagainsttheThirdPartyinaccordancewiththetermsofthisContract.Thepartiesshallnotbeliableforanylossessufferedtheotherpartyasaresultofsuchbreachordefault.16.5第三方權(quán)利限制劃分TheThirdPartyshallnothaveanyrightsunderthisContractotherthanthoseexpresslyprovidedforinthisContract.ThepartiesshallnotberesponsibleforanyclaimsordemandsmadetheThirdParty.16.6第三方解除合同劃分TheThirdPartymaynotterminatethisContractunlessthepartiesagreeinwritingtosuchtermination.ThepartiesshallnotbeliableforanycostsorexpensesincurredtheThirdPartyinconnectionwithsuchtermination.16.7第三方保險(xiǎn)劃分TheThirdPartyshallberesponsibleforobtainingandmaintainingallnecessaryinsurancecoverageinaccordancewiththetermsofthisContract.ThepartiesshallnotberesponsibleforanycostsorexpensesincurredtheThirdPartyinobtainingormaintainingsuchinsurancecoverage.16.8第三方合規(guī)劃分TheaboveprovisionsshallapplytoanyThirdPartyinvolvedintheperformanceofthisContractandshallbebindingonthepartieshereto.第三部分：其他補(bǔ)充性說明和解釋說明一：附件列表：1.合同主體資質(zhì)證明2.設(shè)計(jì)與施工內(nèi)容詳細(xì)說明3.合同金額與支付方式詳細(xì)說明4.設(shè)計(jì)與施工期限詳細(xì)說明5.質(zhì)量標(biāo)準(zhǔn)與要求詳細(xì)說明6.技術(shù)與資料交換詳細(xì)說明7.變更與調(diào)整詳細(xì)說明8.保險(xiǎn)責(zé)任詳細(xì)說明9.合同生效、變更與終止詳細(xì)說明10.保密條款詳細(xì)說明11.環(huán)境影響與安全詳細(xì)說明12.第三方介入詳細(xì)說明13.附件清單（包括所有附件的名稱和編號(hào)）14.違約行為及責(zé)任認(rèn)定詳細(xì)說明說明二：違約行為及責(zé)任認(rèn)定：1.設(shè)